Welcome to Web Developer! These Terms of Service (“Terms”) govern your use of our website and web development services. By accessing our website or engaging in our services, you agree to comply with and be bound by the following terms.
1. Acceptance of Terms
By accessing and using our services, you acknowledge that you have read, understood, and agree to be bound by these Terms, as well as any applicable laws and regulations. If you do not agree with these Terms, you should not use our website or services.
2. Services Provided
Web Developer provides professional web development services, including but not limited to:
- Website Design and Development
- Custom Web Solutions
- E-commerce Development
- Website Maintenance and Support
The scope and details of services will be outlined in a separate agreement between you and Web Developer based on your project requirements.
3. Client Responsibilities
To ensure the successful completion of your project, you agree to:
- Provide Necessary Information: Timely provide all content, graphics, and project-related materials necessary for development.
- Cooperate in Good Faith: Offer feedback and approvals as required, and respond to communications in a timely manner.
- Adhere to Payment Terms: Comply with the agreed-upon payment terms outlined in the service agreement or invoice.
Failure to meet these responsibilities may result in project delays, additional fees, or termination of services.
4. Payment Terms
- Deposits: A 100% deposit is required to begin any project.
- Milestone Payments: Payments are structured around project milestones, as outlined in the service agreement.
- Final Payment: The remaining balance is due upon completion of the project, before final delivery or deployment.
- Late Payments: Any invoices not paid within [number] days of the due date will be subject to late fees or interest as per the service agreement.
If you fail to make the necessary payments, Web Developer reserves the right to withhold delivery of work and cease all ongoing development activities.
5. Revisions and Changes
- Scope of Work: Any revisions or modifications beyond the agreed-upon project scope will be billed separately.
- Revision Requests: Clients are entitled to WhatsApp rounds of revisions for each project milestone. Any additional revisions may incur extra fees.
6. Intellectual Property
- Client Content: You retain all intellectual property rights to the content (text, images, etc.) you provide to [Your Company Name] for the project.
- Work Product: Upon full payment, you will own the final website or project deliverable, including any custom designs, code, or documentation created specifically for your project.
- Third-Party Materials: Any third-party software, plugins, or resources used in your project are subject to their respective licenses, and you agree to comply with those terms.
7. Confidentiality
Both parties agree to maintain the confidentiality of any proprietary or sensitive information shared during the course of the project. This includes business plans, technical data, client data, and other confidential materials. Confidential information will not be disclosed to any third party without prior written consent, except as required by law.
8. Termination of Services
- By Client: You may terminate the project at any time by providing written notice. In such cases, you will be billed for all work completed up to the termination date.
- By Web Developer: We reserve the right to terminate the project or service if the client breaches any of these terms or fails to fulfill agreed-upon obligations.
- Refunds: Refunds will be issued in accordance with our [Refund Policy], and any applicable fees or expenses incurred will be deducted from the refund amount.
9. Warranties and Disclaimers
- Limited Warranty: We guarantee that the final deliverables will substantially meet the agreed-upon specifications. If any defects are discovered within WhatsApp days of delivery, we will make the necessary corrections at no extra charge.
- No Further Warranties: Web Developer makes no warranties regarding third-party products, plugins, or external integrations used in the project.
- Disclaimers: We are not responsible for any issues that arise from the client’s hosting provider, third-party services, or unforeseen technical difficulties beyond our control.
10. Limitation of Liability
To the fullest extent permitted by law, Web Developer shall not be liable for any indirect, incidental, or consequential damages arising out of or related to the use of our services, including but not limited to loss of revenue, data, or profits, even if we have been advised of the possibility of such damages.
11. Governing Law
These Terms shall be governed by and construed in accordance with the laws of Bangladesh. Any disputes arising under or in connection with these Terms shall be resolved through negotiation or, if necessary, in the courts located in [Your Jurisdiction].
12. Changes to Terms
We reserve the right to modify these Terms at any time. Any changes will be posted on this page with an updated effective date. Your continued use of our services after any changes signifies your acceptance of the updated Terms.
13. Contact Information
If you have any questions or concerns regarding these Terms, please contact us at:
